【 Weak current College 】 renovation contract model for painting

In accordance with the contract of and People's Republic of China concerning the laws and regulations, in conjunction with family room decoration engineering construction characteristics, the two sides in equality, voluntary, on the basis of consensus, the constructer of household decoration Engineering (engineering), reached the following agreements: contract number: ______ constructer: contractor: Home: Home: Agent: business license numbers: Tel: legal representative: Tel: BP machine number: Agent: telephone: engineering design: Tel: construction team principal: Tel: in accordance with the contract of and People's Republic of China concerning the laws and regulations, in conjunction with family room decoration engineering construction characteristics, the two sides in equality, voluntary, on the basis of consensus, the constructer of household decoration Engineering (engineering), reached the following agreements: the first project profiles 1.1 project location: ___________________. 1.2 engineering content and practices (see attached table 1: the family room decoration engineering construction project confirmation form. Schedule 2: family room decoration engineering content and practices of the list). 1.3 project Contracting: the two sides agreed to take the following forms of contract ___. (1) the contractor outworkers, package material (see attached table 5: contractor provides detailed decoration material); (2) the contractor outworkers, part of the package, provide part of the material contract (see attached table 4: letting people provide decoration materials list. Schedule 5: contractor provides detailed decoration material); (3) the contractor, contractor, contract person package material (see attached table 4: letting people provide decoration materials list). 1.4 project deadline date ____ days started month in ____ ____ ____ ____, completion date ____ ____ day month year. 1.5 contract price: this contract engineering cost (capital): $ ____________ (see attached table 3: family room decoration project quotation). The second project supervision if this project implementation project management, Contracting and project management company announced the signing of the contract of construction supervision and management engineer of the name, organization, contact details and the responsibilities of the supervisor engineer informed the contractor. Article 3, the two sides agreed on construction of the blueprints construction drawings to ___ way provides: (1) letting people to design and construction drawings, blueprints provide duplicate contract, a contractor (see attached table 6: family room decoration design drawings); (2) contract authorized contractor design drawings of a construction drawings, in duplicate, letting people, with a copy of the contractor (see attached table 6: family room decoration design drawings), design (uppercase) $ ______, by letting people pay (this fee is not in the project account). Article 4 obligations 4.1 constructer ____ days, before starting to create the conditions for admission and construction contractor. Including: moving Qing furniture, furnishings or indoor hard carry furniture, furnishings to heap, cloaking, without affecting the principle of construction; 4.2 provides construction period of water, and power; 4.3 is responsible for coordinating construction team and neighbourhood relations; 4.4 not demolition dynamic Interior load-bearing structure, need to remove the original construction of non-load-bearing structure or device pipeline, responsible for the relevant departments for the examination and approval procedures; 4.5 construction contract person still need to use the room, is responsible for doing the construction site of items such as security and fire safety; 4.6 participation project quality supervision and construction progress, is responsible for the material inside the venue, and acceptance. Article 5 obligations 5.1 construction contractor to strictly enforce safe construction practices, fire regulations, construction specifications and quality standards, regular and complete the project; 5.2 strictly enforce the provisions of the construction site management, not disturbing and pollute the environment; 5.3 protect original interior furniture and furnishings, living room, water pipeline flow; 5.4 guarantee the construction site, project completion is responsible for cleaning the construction site. 6 engineering change projects and construction methods if you want to change, the Parties shall by consensus, entered into a written agreement, the change also adjust the related project costs and durations (see table 7: family room decoration engineering change orders). 7 material provided by letting people provide 7.1 materials and devices (see attached table 4: letting people provide decoration materials list), the contract should be in the materials to the construction site, notify the contractor before the mutual acceptance and handling handover procedures provided by the contractor; 7.2 materials and devices (see attached table 5: contractor providing decoration materials list), the contractor should be in the materials to the construction site before the contract, and accepted the constructer inspection.
Article 8 delay 8.1 caused delays in the completion of the contract were confirmed, duration correspondingly: (1) changes in the amount of engineering and design changes; (2) force majeure; (3) contract duration extended by consent of the other circumstances. 8.2 constructer not due as agreed to complete its work should be responsible for the effect duration, duration extended from constructer of materials, equipment quality and affect the quality of the project, the costs by letting people rework, duration extended. 8.3 letting people not paid engineering, contract duration correspondingly. The contractor responsible for 8.4 cannot be started or stopped and influenced without intermediate duration, duration of contractor is not postponed, for reasons of quality problems, rework costs borne by the contractor, the duration is not postponed. Article 9, the two sides agreed quality standards of construction quality standard: ___________________________________________. Construction on the quality of the project in the event of a dispute, by the Department on project quality _________ be certification, quality of accredited engineering does not conform to the contractStandards, certification process expenses borne by the contractor related to costs; certified engineering quality meet contractual standards, certification process expenditure related costs borne by letting people. Article 10 the engineering acceptance and warranty 10.1 agreed in the construction process is divided into the following stage of project quality acceptance: _________________________ (1); (2) _________________________; (3) _________________________. The contractor shall notify Contracting two days in advance for acceptance, the stage after the acceptance of project acceptance form should be completed (see schedule 8: family room decoration engineering acceptance form). After completion, the project 10.2 contractor shall inform the constructer acceptance, the contract shall, after receiving the approval notification within two days, fill out the engineering organizations acceptance acceptance form (see annex 8: family room decoration engineering acceptance form). In the project shall settle the transfer procedures after processing (see attached table 9: family room decoration engineering???). 10.3 this project acceptance both parties signature date ____ month warranty is available. Signature of acceptance, the complete works of warranty (see table 10: the family room decoration engineering warranty). 11 payment way the two sides agreed on the following 11.1 ____ way paid work: (1) after the entry into force of the contract, the contract according to the conventions in the following table directly to paid contractor:--------------------------------------｜ payment times | payment time | payments | |--------|-----------|-----------| | first | pre-construction 3 | $ | payment | second half £ ü ü project progress payment of $ ｜ ｜ third | mutual acceptance | pay element |------------------------------------------half means: ________________________________________. （2）其他支付方式：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿。 11.2 engineering acceptance, the contractor shall submit project settlement constructer and relevant information to the contract. After receiving the information constructer ____ days if no objection is taken to agree, the Parties shall complete the works sheet (annex 9: family indoor decoration works???) and signed by the person who should be in the contract signature to the contractor settlement prior to the project. 11.3 project fund all settled, the contractor shall draw up a formal constructer uniform invoice. Article 12: liability for breach of contract 12.1 in any of the parties, a party because of non-fulfilment of contract or violation of national laws, regulations and policies, subject to a fine or to offset losses caused by the responsible party liability and compensation for economic losses caused by the other. 12.2 does not go through the acceptance process, letting people ahead of the use or unauthorized use of works in the finished product and the damage caused by the contract. 12.3 due to reasons, a party is unable to continue performing the contract, that party shall promptly notify the other party for the termination of the contract, and by the responsible party for each corresponding economic losses. 12.4 contract have not paid the second (third) time of the project, every day of delay to pay liquidated damages of $ ____. 12.5 contractors, engineering quality does not meet the quality standards agreed upon by both parties, the contractor shall not be responsible for the repair, duration the deadline. The reasons for which the contractor 12.6 as the delay, the delay each day to pay liquidated damages of $ ____. 13 contracts dispute resolution methods in fulfilling this contract during the dispute resolved through consultation by both parties or by the relevant sector mediation; consultations or mediation, the following paragraph __ ways: (1) ________ arbitration; (b) court proceedings according to law. Article 14 several specific provisions 14.1 because construction of waste resulting from the contractor is responsible for removal from the construction site, and is responsible for the spam sent to the specified locations, letting people is responsible for paying the costs of waste removal (uppercase) ________ Yuan (this fee is not in the project account). 14.2 during the construction, Contracting will be key to the ____ waiwu, to the custody of the contractor. Engineering completion approval, letting people responsible for providing new locks the ____, the contractor is responsible for the installation on the spot. 14.3 construction period, the contractor's work time as a day: morning ____ ___ ___ point to point ___ ___ point; afternoon to ___ ___ ___ point. 第十五条 其他约定事项：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿。 16 Annex 16.1 this contract signed by both parties after the entry into force (seal), after the termination of the contract. 16.2 after hereof shall not subcontract engineering. 16.3 this contract ___, ____ copy for each party, ____________ ____ sector. 16.4 contract annex to part of this contract, and this contract have the same legal effect. Contract Annex: Schedule 1 – 1: family room decoration engineering construction projects confirm table (a) Schedule 1 — 2: family room decoration engineering construction project acknowledgment form (2) Schedule 2: family room decoration engineering content and practices list 3: family room decoration engineering quotes Schedule 4: letting people provide decoration materials schedule schedule: the contractor may provide decoration materialFor a detailed schedule 6: family room decoration design drawing Schedule 7: family room decoration engineering change single schedule 8: family room decoration engineering acceptance certificate of Schedule 9: family room decoration engineering statement schedules 10: family room decoration engineering warranty form letting people (signature): contractor (seal): legal representative: Agent: year month day year month day---------------------------------forensic views: forensic authorities (chapter) Attn: year month day---------------------------------producer sector: printing units: