【 Weak current College 】 latest renovation contract templates

Contract number: ______
Contract person: contractors:
Accommodation: accommodation:
Agent: business license number:
Phone: legal representative: telephone:
BP machine number: Agent: telephone:
The Project Designer: telephone:
Construction team Conveners: telephone:
In accordance with the law of contracts and related People's Republic of China law, regulations, combined with family room decoration engineering construction characteristics, both parties in equal, voluntary, on the basis of consensus, the constructer of household decoration Engineering (engineering) related matters, reached the following agreement:
The first project overview
1.1 project location: ___________________.
1.2 engineering content and practices (see attached table 1: the family room decoration engineering construction projects confirm table. Schedule 2: family room decoration engineering content and practices of the list).
1.3 project Contracting: the two sides agreed to take the following forms of contract ___.
(1) the contractor, contractor, package material (see attached table 5: contractor providing decoration materials list);
(2) the contractor, contractor, part of the package material, provide part of the material contract (see attached table 4: letting people provide decoration material list. Schedule 5: contractor providing decoration materials list);
(3) the contractor, contractor, contract person package material (see attached table 4: letting people provide decoration materials list).
1.4 project deadline date ____ days, start month in ____ ____ ____ ____, completion date ____ ____ day month year.
1.5 contract price: this contract engineering cost (capital): $ ____________ (see attached table 3: family room decoration project quotation).
The second project supervision
If this project implementation project management, Contracting and project management company announced the signing of the contract, project supervision and management engineer's name, organization, contact details and the responsibilities of the supervisor engineer informed the contractor.
Article 3 the construction drawings
The two sides agreed on construction drawings to ___ way provides:
(1) letting people to design and construction drawings, two copies of drawings, letting people, with a copy of the contractor (see attached table 6: family room decoration design drawings);
(2) contract authorized contractor design drawings of a construction drawings, in duplicate, letting people, with a copy of the contractor (see attached table 6: family room decoration design drawings), design (uppercase) $ ______, by letting people pay (this fee is not in the project account).
Article 4 obligations constructer
4.1 pre-construction ____ days, to create the conditions for admission and construction contractor-including: moving Qing furniture, furnishings or indoor furniture is not easy to carry, and display to the heap, cloaking, without affecting the principle of construction;
4.2 provides construction of water supply, power supply;
4.3 is responsible for coordinating construction team and relations between neighbours;
4.4 not demolition dynamic Interior load-bearing structure, such as the need to remove the original construction of non-load-bearing structure or device pipeline, responsible for the relevant departments for the examination and approval procedures;
4.5 construction contract person still need to use the room, is responsible for doing the construction site of items such as security and fire safety;
4.6 participation project quality supervision and construction progress, is responsible for the material inside the venue, and acceptance.
Article 5 obligations of the contractor
5.1 construction strictly enforced code of safe construction, fire safety, construction specifications and quality standards, regular and complete the project;
5.2 strictly enforce the provisions of the construction site management, no nuisance and pollution of the environment;
5.3 protect original interior furniture and furnishings, living room, water pipeline flow;
5.4 guarantee the construction site of neat, project completion is responsible for cleaning the construction site.
6 engineering change
Project and construction methods if you want to change, the Parties shall by consensus, entered into a written agreement, the change also adjust the related project costs and durations (see table 7: family room decoration engineering change orders).
7 material provided
7.1 from constructer of materials, devices (see attached table 4: letting people provide decoration materials list), the contract should be in the material sent to notify the contractor in the construction site, mutual acceptance and transfer of procedures;
7.2 by information provided by the contractor, equipment (see attached table 5: contractor providing decoration materials list), the contractor should be in the materials to the construction site before the contract, and accepted the constructer inspection.
8 duration of delay
8.1 caused delays in the completion, by letting people confirm that duration correspondingly:
(1) engineering changes and design changes;
(2) force majeure;
(3) contract duration extended by consent of the other circumstances.
8.2 constructer not due as agreed to complete its work should be responsible for the effect duration, duration extended; by letting people provided materials, equipment quality and affect the quality of the project, costs by letting people rework, duration extended.
8.3 letting people not paid engineering, contract duration correspondingly.
The contractor responsible for 8.4 cannot be started or stopped halfway without cause and affect the duration of that period is not extended; as a result of the contractor caused problems of project quality, rework costs borne by the contractor, the duration is not postponed.
9 quality standards
The parties agreed the project construction quality standard: ___________________________________________.
Construction on the quality of the project in the event of a dispute, by the Department on project quality _________ be certified, certified quality does not meet the contractualStandards, certification process expenses borne by the contractor related to costs; certified engineering quality meet contractual standards, certification process expenditure related costs by letting people assume.
Article 10 the engineering acceptance and warranty
10.1 agreed in the construction process is divided into the following stage of project quality for acceptance:
(1)_________________________;
(2)_________________________;
(3)_________________________.
The contractor shall notify Contracting two days in advance for acceptance, stage after the acceptance of project acceptance form should be completed (see schedule 8: family room decoration engineering acceptance form).
After completion, the project 10.2 contractor shall inform the constructer acceptance, the contract shall, after receiving the approval notification within two days, fill out the engineering organizations acceptance acceptance form (see annex 8: family room decoration engineering acceptance form). in the cleared after work, go through the transfer procedures (see attached table 9: family indoor decoration works???).
10.3 this project acceptance both parties signature date ____ months warranty period for the qualified signature., fill in the warranty Bill project (see table 10: the family room decoration engineering warranty).
11 payment methods
The two sides agreed on the following 11.1 ____ way pay works fine:
(1) after the entry into force of the contract, the contract according to the conventions in the following table directly to the project: the contractor pays the
--------------------------
| Payment times | Payment time | Payments |
|------|--------|--------|
| First | Pre-construction 3 | Pay $ |
| Second | Half | progress Pay $ |
| Third | Mutual acceptance | Pay $ |
--------------------------
工程进度过半指:________________________________________.
(2)其他支付方式:_______________________________________.
11.2 engineering acceptance, the contractor shall submit project settlement constructer and relevant information to the constructer. after receiving information on the constructer ____ days if no objection is taken as agreed that the parties should complete the works sheet (annex 9: family indoor decoration works???) and signature, the signature should be in the constructer to settle works prior to the contractor.
11.3 project fund all settled, the contractor shall draw up a formal constructer uniform invoice.
Article 12: liability for breach of
12.1 contract parties any party failing to fulfil the contract or the breach of national legislation, regulations and policies, subject to a fine or to offset losses caused by the responsible party, and compensation to each other causing economic losses.
12.2 does not go through the acceptance process, letting people ahead of the use or unauthorized use of engineering product loss by letting people responsible.
The reason for a party 12.3, resulting contract cannot continue to fulfil, the Party shall promptly notify the other party, for termination of the contract, and by the responsible party for each corresponding economic losses.
12.4 contract have not paid the second (third) time works fine, every day of delay to pay liquidated damages of $ ____.
12.5 contractors, engineering quality does not meet the quality standards agreed upon by both parties, the contractor shall not be responsible for the repair, duration the deadline.
The reasons for which the contractor 12.6 as the delay, the delay each day to pay liquidated damages of $ ____.
Article 13 of the contract dispute resolution
In fulfilling this contract during the dispute, resolved by consultation between the parties; or by the relevant sector mediation; consultations or mediation fails, the following section ____ way solve:
(A) ________ arbitration;
(Ii) the law to the Court.
Article 14 the number of specific provisions
14.1 due to construction and production of waste, by the contractor is responsible for removal from the construction site, and will be responsible for the spam sent to the specified locations, letting people is responsible for paying the costs of waste removal (uppercase) ________ Yuan (this fee is not in the project account).
14.2 construction period, the contract will be key to the ____ waiwu, handed over to the contractor's custody after acceptance. engineering, letting people responsible for providing new locks the ____, the contractor is responsible for the installation of delivery on the spot.
14.3 construction period, the contractor's work time per day: morning ____ ___ ___ point to point score; afternoon ___ ___ ___ ___ point to point ___ minutes.
第十五条 其他约定事项:_____________________________________________________________________________.
Article 16: supplementary provisions
16.1 this contract signed by both parties after the entry into force (seal), after the termination of the contract.
16.2 after hereof shall subcontract.
16.3 this contract ____ copies, each party a ____________ ____ ____ copies, departments.
16.4 contract annex to part of this contract, and this contract have the same legal effect.
Contract Annex:
Schedule 1 – 1: family room decoration engineering construction projects confirm table (a)
Schedule 1-2:Family room decoration engineering construction project acknowledgment form (2)
Schedule 2: family room decoration engineering content and practices checklist
Schedule 3: family room decoration engineering quotes
Schedule 4: letting people provide decoration materials list
Schedule 5: contractor providing decoration materials list
Schedule 6: family room decoration design drawings
Table 7: family room decoration engineering change orders
Table 8: domestic indoor decoration works acceptance form
Table 9: family room decoration engineering???
Table 10: the family room decoration engineering warranty contract (signature): contractor (seal):
Legal representative:
Agent: year month day year month day-------------------------
Views: forensic laboratory, organs (chapter)
Attn:
Year month day
-------------------------
Producer sector: printing units: